Loading...
HomeMy WebLinkAboutResolution 2023-125 Approving and Authorizing the Town Manager to Execute an Airport Development Reimbursable Grant AgreementMARANA RESOLUTION NO.2023-125 RELATING TO THE MARANA REGIONAL AIRPORT; APPROVING AND AUTHORIZING THE TOWN MANAGER TO EXECUTE AN AIRPORT DEVELOPMENT REIMBURSEABLE GRANT AGREEMENT IN THE AMOUNT OF $20,854.00 BETWEEN THE STATE OF ARIZONA, BY AND THROUGH THE DEPARTMENT OF TRANSPORTATION (ADOT), AND THE TOWN OF MARANA FOR THE PURPOSE OF AIDING IN FINANCING THE AIR TRAFFIC CONTROL TOWER ENVIRONMENTAL ASSESSMENT PROJECT (GRANT NO. E4FSS 01E) WHEREAS A.R.S. § 28-8411 authorizes the Town Council of the Town of Marana to undertake all activities necessary to acquire, establish, construct, own, control, lease, equip, improve, maintain, operate, and regulate an airport; and WHEREAS A.R.S. § 28-8413 authorizes the Town to accept and receive federal and other monies for the acquisition, construction, enlargement, improvement, maintenance, equipment, or operation of an airport and to enter into agreements regarding the receipt of such monies; and WHEREAS the purpose of the Airport Development Reimbursable Grant Agreement (Grant No. E4FSS 01E) is to provide $20,854.00 in State funding to aid in financing the Air Traffic Control Tower Environmental Assessment for the Marana Regional Airport (the "Project"); and WHEREAS the terms of the grant agreement require the Town to certify certain information by resolution approved by the Marana Town Council; and WHEREAS the Mayor and Council feel it is in the best interests of the Town and its citizens to enter into the grant agreement and to certify the information required by the agreement. NOW, THEREFORE, BE IT RESOLVED BY THE MAYOR AND COUNCIL OF THE TOWN OF MARANA, ARIZONA, AS FOLLOWS: SECTION 1. The Town hereby certifies that (1) the Town has the legal power and authority to do all things necessary in order to undertake and carry out the Project, and to accept, receive, and disburse grant funds from the State in aid of the Project; (2) the Town now has on deposit, or is in a position to secure, $20,854.00, or an equivalent amount represented by the Towri s proposed labor and equipment costs, for the use in -1- Resolution No. 2023-125 defraying Sponsor's share of the costs of the Project; (3) the Town designates its Finance Director, Yiannis Kalaitzidis, to receive payments representing the State's share of Project costs; and (4) the Town has on file with ADOT a vendor identification and address for Project payments. SECTION 2. The Airport Development Reimbursable Grant Agreement (Grant No. E4FSS 01E), substantially in the same form attached to and incorporated by this reference in this resolution as Exhibit A, is hereby approved and authorized and the Towri s Manager and staff are hereby directed and authorized to undertake all other and further tasks required or beneficial to carry out the terms, obligations, and objectives of this resolution. PASSED AND ADOPTED by the Mayor and Council of the Town of Marana, Arizona, this 19th day of December, 2023. ATTEST: David L. Udall, Town Clerk MARANA AZ ESTABLISHED 1977 Mayor Ed Honea APPR D AS TO FOR : J e airall, Town Attorney -2- Resolution No. 2023-125 Grant Number E4FSS 01E TOWN OF MARANA Marana Regional Airport Arizona Department of Transportation Multimodal Planning Division Aeronautics Group Airport Development Reimbursable Grant Agreement Part I THIS AGREEMENT is entered into , between the STATE OF ARIZONA, acting by and through its DEPARTMENT OF TRANSPORTATION, through its Multimodal Planning Division (the "State") and TOWN OFMARANA, a political subdivision of the State of Arizona, (the "Sponsor") for a grant of State funds for the purpose of aiding in financing a Project of Air Traffic Control Tower Environmental Assessment (the "Project"), for the improvement of the Marano Regional Airport (the "Airport"). WITNESSETH Roritnic- 1) The Sponsor desires, in accordance with the authority granted by Arizona Revised Statutes (A.R.S.) Section 28-8413, funds from the State for the purpose of airport planning and/or development. 2) The Arizona State Transportation Board, as approved on October 20, 2023, and the Director of the Arizona Department of Transportation, in accordance with the authority granted by A.R.S. Sections 28-304, 28-363, and 28- 401 and Title 28, Chapter 25, A.R.S., have authorized reimbursement to the Sponsor of funds expended for airport planning and/or development. Now, therefore, in consideration of the foregoing recitals and of the covenants and agreements made by the parties herein to be kept and performed, the parties agree as follows: Sponsor's Responsibility 1) The Sponsor shall accept this Agreement within 4 months of the date of the grant offer cover letter: October 30, 2023. This Grant offer, if not accepted by the Sponsor, shall expire at the end of the 4-month period. 2) The Sponsor shall commence the Project within 6 months of the date the grant was executed by the State. This Project will consist of the airport improvements as described in Exhibit C. The Sponsor shall proceed with due diligence and complete the Project in accordance with the provisions of this Agreement. The Sponsor shall provide and maintain competent supervision to complete the Project in conformance with the plans, specifications and work completion schedule incorporated as part of this Agreement. Page 1 of 20 Grant Number E4FSS 01E TOWN OF MARANA Marana Regional Airport 3) The Sponsor shall submit completed Project Reimbursement and Milestone schedules, which shall be attached hereto, as Exhibit C, Schedules Two and Three respectively and shall complete the Project within that schedule. Any change to the schedule shall be submitted in writing and be approved by the State. A time extension beyond the State's obligation to provide funds herein must be reflected by formal Amendment to this Agreement. 4) The Sponsor shall comply with the Sponsor Assurances and abide by and enforce the General Provisions and Specific Provisions incorporated herein as Exhibits A, B and C respectively. Obligations 1) The minimum funding participation from the Sponsor shall be $20,854.00 4.47(°o) participation as determined by the State. 2) The maximum reimbursement available from the State to the Sponsor for this Agreement shall be Twenty Thousand Eight Hundred Fifty Four Dollars $20,854.00. 3) Except as otherwise provided herein for the State's obligation to provide funds hereunder expires upon completion of the Project required herein or October20, 2027, whichever is earlier. 4) The State may, after agreeing to provide said funds to the Sponsor, withdraw/terminate the grant if the Project has not been initiated as evidenced by a Notice to Proceed within 6 months of the date the grant was executed by the State or has not progressed as scheduled over a period of 12 months or if the State determines that Sponsor is not otherwise complying with the terms of this Agreement. If it becomes necessary to terminate a grant at any time, the State will reimburse expenses of the Sponsor, approved by the State, up to the time of notification of cancellation provided Sponsor is not in default hereunder. 5) Sponsor acknowledges that in the event of a late payment or reimbursement by the State, the State shall have no obligation to pay a late payment fee or interest and shall not otherwise be penalized. 6) Notwithstanding anything to the contrary herein, in the case where funds are no longer available or have been withdrawn or not appropriated, or the Project is no longer in the State's best interest, the State shall have the right of termination at its sole option. The State shall not reimburse any costs incurred after receipt of the notice of termination. The Governor pursuant to A.R.S. Section 38-511 hereby puts all parties on notice that this Agreement is subject to cancellation. Preliminary Work Provision Any preliminary work, for which costs for this Project were incurred after 2/9/2023 shall be considered eligible for reimbursement provided that said costs are directly related to the Project on which this Agreement is written. The State shall review related records and determine eligibility at its sole discretion. Page 2 of 20 Grant Number E4FSS HE TOWN OF MARANA Marana Regional Airport Part II The Sponsor shall approve and attach to this agreement a resolution, or Motion, or Board Action by its governing body that certifies as follows: 1) The Sponsor has the legal power and authority: a) to do all things necessary, in order to undertake and carry out the Project; b) to accept, receive and disburse grant funds from the State in aid of the Project. 2) The Sponsor now has on deposit, or is in a position to secure Twenty thousand eight hundred fifty four dollars ($ 20,854.00 ), or an equivalent amount represented by Sponsor's proposed labor and equipment costs, for use in defraying Sponsor's share of the costs of the Project. The present status of these funds is as follows: _Town of Marana General Fund (Enter local funding type and location) 3) The Sponsor hereby designates _Yiannis Kalaitzdis , Finance Director Name Title to receive payments representing the State's share of project costs. Signature of Sponsor's Representative Town Manager Title of Representative 4) The Sponsor has on file with ADOT the following vendor identification and address for project payments: Sponsor Vendor Id # Sponsor Vendor Address Exhibits IV0000001820 TOWN OF MARANA 11555 W. Civic Ctr Dr, Marana, AZ 85653 The following Exhibits are incorporated herewith and form a part of this Agreement. Exhibit A - Sponsor Assurances Exhibit B - General Provisions Exhibit C - Specific Provisions and Project Schedules Page 3 of 20 STATE: SPONSOR: State of Arizona Department of Transportation Multimodal Planning Division By: Title: MPD Division Director Date: WITNESSED BY: Signature: Print Name: Date: Grant Number E4FSS HE TOWN OF MARANA Marana Regional Airport TOWN OF MARANA Marano Regional Airport By: _Terry Rozema Title: _Town Manager Date: WITNESSED BY: Signature: Print Name: Date: Page 4 of 20 Grant Number E4FSS 01E TOWN OF MARANA Marana Regional Airport FXHIRIT A Sponsor Assurances Upon acceptance of the grant offer by the Sponsor, these assurances will become a part of this Agreement. The Sponsor hereby covenants and agrees with the State as follows: General 1) That the Project is consistent with plans (existing at the time of approval of the Project) of political jurisdictions authorized by the State to plan for the development of the area surrounding the Airport and has given fair consideration to the interest of communities in or near where the Project is to be located. In making a decision to undertake any airport development Project under this Agreement the Sponsor insures that it has undertaken reasonable consultation with affected parties using the Airport at which the Project is proposed. All appropriate development standards of Federal Aviation Administration (FAA) Advisory Circulars, Orders, or Federal Regulations shall be complied with. All related state and federal laws shall be complied with. 2) That these covenants shall become effective upon execution of this Agreement for the Project or any portion thereof, made by the State and shall remain in full force and effect throughout the useful life of the facilities or the planning project's duration developed under the grant, but in any event, not less than twenty (20) years from the date of acceptance of the grant offer by the Sponsor. 3) The Sponsor certifies in this Agreement that it is a political subdivision of the State and is the public agency with control over a public -use Airport and/or on behalf of the possible future development of an Airport and is eligible to receive grant funds for the development or possible development of an Airport under its jurisdiction. 4) The Sponsor further agrees it holds good title, satisfactory to the State, to the landing area of the Airport or site thereof, or will give assurance satisfactory to the State that good title will be acquired. 5) That the Sponsor is the owner or lessee of the property or properties on which the Airport is located and that the lease guarantees that the Sponsor has full control of the use of the property for a period of not less than twenty (20) years from the date of this Agreement. All changes in airport ownership or to an airport lease shall be approved by the State. 6) The Sponsor agrees that it has sufficient funds available for that portion of the project costs which are not to be paid by the State (or the United States). 7) The Sponsor agrees to provide and maintain competent supervision to complete the Project in conformance with this Agreement. 8) Preserving Rights and Powers: The Sponsor agrees it shall not take or permit any action which would operate to deprive it of any of the rights and powers necessary to perform any or all of the terms, conditions and assurances in this Agreement without written permission from the State, and shall act promptly to acquire, extinguish or modify any outstanding rights or claims of right by others which would interfere with such performance by the Sponsor. This will be done in a manner acceptable to the State. The Sponsor shall not sell, lease, encumber or otherwise transfer or dispose of any part of its title or other interests in the property shown on the airport property map included in the most recent FAA -approved Airport Layout Plan, or to that portion of the property upon which State Page 5 of 20 Grant Number E4FSS 01E TOWN OF MARANA Marana Regional Airport funds have been expended, for the duration of the terms, conditions and assurances in this Agreement without approval by the State. If the transferee is found by the State to be eligible under Title 49, United States Code, to assume the obligations of this Agreement and to have the power, authority and financial resources to carry out such obligations, the Sponsor shall insert in the contract or document transferring or disposing of Sponsor's interest and make binding upon the transferee all the terms, conditions and assurances contained in this Agreement. 9) Public Hearings: In Projects involving the location of an Airport, an airport runway or a major runway extension, the Sponsor has afforded the opportunity for public hearings for the purpose of considering the economic, social and environmental impacts of the Airport or runway location and its consistency with goals and objectives of such planning as has been carried out by the community and it shall, when requested by the State, submit a copy of such hearings to the State. Financial Pursuant to A.R.S. 35-326, the Sponsor may elect to utilize the Local Government Investment Pool ("LGIP") maintained by the state treasurer. The Sponsor shall request written approval from the State to use the LGIP. Thereafter, the State may deposit the funds authorized by the grant into the Sponsor's account. After approval of the reimbursements by the state, the funds shall be disbursed through the LGIP account to the Sponsor. The disbursements shall be made pursuant to the applicable laws and regulations. The Sponsor shall establish and maintain for each Project governed by this Agreement, an adequate accounting record to allow State personnel to determine all funds received (including funds of the Sponsor and funds received from the United States or other sources) and to determine the eligibility of all incurred costs of the Project. The Sponsor shall segregate and group project costs into cost classifications as listed in the Specific Provisions of Exhibit C. Record Keeping The Sponsor shall maintain accurate records of all labor, equipment and materials used in this Project and that upon reasonable notice, shall make available to the State, or any of their authorized representatives, for the purpose of audit and examination all records, books, papers or documents of the recipient relating to work performed under this Agreement. For airport development Projects, make the Airport and all airport records and documents affecting the Airport, including deeds, leases, operation and use agreements, regulations and other instruments, available for inspection by any duly authorized agent of the State upon reasonable request. Airport Based Aircraft Reporting The Sponsor shall furnish to the State on a quarterly basis, a current detailed listing (including: Registration/N Number, Name, Address and Phone Number of Owner) of all based aircraft on the Airport in a form approved by the State. Airport Layout Plan 1) The Sponsor shall maintain a current signed/approved Airport Layout Plan (ALP) of the Airport, which shows building areas and landing areas, indicating present and planned development and to furnish the State an updated ALP of the Airport as changes are made. 2) The Sponsor shall be required to prepare an ALP for update or revalidation in accordance with current FAA and State standard guidelines. The ALP will indicate any deviations from FAA design standards as outlined in current FAA Page 6 of 20 Grant Number E4FSS 01E TOWN OF MARANA Marana Regional Airport Advisory Circulars, orders or regulations. A copy of the signed/approved ALP in electronic format shall be forwarded to the State after authentication by FAA or the State. 3) The Sponsor shall assure that there are no changes to the airport property boundaries, together with any off -site areas owned or controlled by the Sponsor which support the Airport or its operations as a part of this project. 4) If a change or alteration is made at the Airport which the State determines adversely affects the safety, utility or efficiency of the Airport, or any State funded property on or off Airport which is not in conformity with the ALP as approved by the State, the Sponsor will, if requested by the State, eliminate such adverse affect in a manner approved by the State. Immediate Vicinity Land Use Restriction The Sponsor shall restrict the use of land, adjacent to or in the immediate vicinity of the Airport, to activities and purposes compatible with normal airport operations and to take appropriate action including the adoption of appropriate zoning laws. In addition, if the Project is for noise compatibility or to protect the 14 CFR Part 77 imaginary surfaces of the Airport, the Sponsor will not cause or permit any change in land use, within its jurisdiction, that will reduce its compatibility, with respect to the Airport, of the noise compatibility program measures or the imaginary surfaces of the Airport upon which State funds have been expended. Airport Operation 1) The Sponsor shall promote safe airport operations by clearing and protecting the approaches to the Airport by removing, lowering, relocating, marking and/or lighting existing airport hazards and to prevent, to the extent possible, establishment or creation of future airport hazards. The Sponsor shall take appropriate action to assure such terminal airspace as is required to protect instrument and visual operations to the Airport (including established minimum flight altitudes) will be adequately cleared and protected by preventing the establishment or creation of future airport hazards. The Sponsor shall promptly notify airmen of any condition affecting aeronautical use of the Airport. 2) The Sponsor further agrees to operate the Airport for the use and benefit of the public and to keep the Airport open to all types, kinds and classes of aeronautical use without discrimination between such types, kinds and classes; provided that the Sponsor shall establish such fair, equal and nondiscriminatory conditions to be met by all users of the Airport as may be necessary for the safe and efficient operation of the Airport; and provided further, that the Sponsor may prohibit any given type, kind or class of aeronautical use of the Airport if such use would create unsafe conditions, interfere with normal operation of aircraft, or cause damage or lead to the deterioration of the runway or other airport facilities. 3) In any agreement, contract, lease or other arrangement under which a right or privilege at the Airport is granted to any person, firm or corporation to conduct or engage in any aeronautical activity for furnishing services to the public at the Airport, the Sponsor shall insert and enforce provisions requiring said person, firm or corporation: a) to furnish services on a reasonable and not unjustly discriminatory basis to all users thereof and charge reasonable and not unjustly discriminatory prices for each unit or service; b) and be allowed to make reasonable and nondiscriminatory discounts, rebates or similar types of price reductions to volume purchasers; Page 7 of 20 Grant Number E4FSS 01E TOWN OF MARANA Marana Regional Airport c) each Fixed Based Operator (FBO) and Air Carrier at the Airport shall be subject to the same rates, fees, rentals and other charges as are uniformly applicable to all other FBOs and Air Carriers making the same or similar uses of the Airport and utilizing the same or similar facilities; d) each Air Carrier using such Airport shall have the right to service itself or to use any FBO that is authorized or permitted by the Airport to serve any Air Carrier at the Airport. 4) The Sponsor shall not exercise or grant any right or privilege which operates to prevent any person, firm or corporation operating aircraft on the Airport from performing any services on its own aircraft with its own employees (including but not limited to maintenance, repair and fueling) that it may choose to perform. In the event the Sponsor itself exercises any of the rights and privileges referred to in this assurance, the services involved will be provided on the same conditions as would apply to the furnishing of such services by a commercial aeronautical operator authorized by the Sponsor under these provisions. 5) The Sponsor shall suitably operate and maintain the Airport and all facilities thereon or connected therewith which are necessary for airport purposes and to prohibit any activity thereon which would interfere with its use for aeronautical purposes and to operate essential facilities, including night lighting systems, when installed, in such manner as to assure their availability to all users of the Airport; provided that nothing contained herein shall be construed to require that the Airport be operated and maintained for aeronautical uses during temporary periods when snow, flood or other climatic conditions interfere substantially with such operation and maintenance. 6) The Sponsor shall not permit an exclusive right for the use of the Airport by any person providing, or intending to provide, aeronautical services to the public. For purposes of this paragraph, providing services at an Airport by a single FBO shall not be construed as an "exclusive right" if: a) it would be unreasonably costly, burdensome or impractical for more than one FBO; and b) if allowing more than one FBO to provide such services would require a reduction of space leased pursuant to an existing agreement between a single FBO and the Airport. Note: Aeronautical activities that are covered by this paragraph include, but are not limited to: charter flights, pilot training, aircraft rental, sightseeing, air carrier operations, aircraft sales and services, aerial photography, agricultural spraying, aerial advertising and surveying, sale of aviation petroleum products whether or not conducted in conjunction with any other aeronautical activity, repair and maintenance of aircraft, sale of aircraft parts, and any other activities which because of their direct relationship to the operation of aircraft can be regarded as an aeronautical activity. 7) The Sponsor shall terminate any exclusive right to conduct an aeronautical activity now existing at the Airport before any grant of assistance from the State. However, there shall be no limit on the duration of the assurances regarding Exclusive Rights and Airport Revenue so long as the Airport is used as an Airport. There shall be no limit on the duration of the terms, conditions, and assurances with respect to real property acquired with State funds. 8) Airport Pavement Preservation Program: The Sponsor certifies that they have implemented an effective pavement preservation management program at the Airport in accordance with Public Law 103-305 and with the most current associated FAA policies and guidance for the replacement, reconstruction or maintenance of pavement at the Airport. The Sponsor assures that it shall use and follow this program for the useful life of the pavement Page 8 of 20 Grant Number E4FSS 01E TOWN OF MARANA Marana Regional Airport constructed, reconstructed or repaired with financial assistance from the State and that it will provide such reports on pavement condition and pavement management programs as may be required by the State. Sponsor Transactions The Sponsor shall refrain from entering into any transaction which would deprive the Sponsor of any of the rights and powers necessary to perform any or all of the covenants made herein, unless by such transaction the obligation to perform all such covenants is assumed by another public agency eligible to assume such obligations and having the power, authority and financial resources to carry out such obligations; and, if an arrangement is made for management or operation of the Airport by an agency or person other than the Sponsor, the Sponsor shall reserve sufficient powers and authority to insure that the Airport will be operated and maintained in accordance with these covenants or insure that such an arrangement also requires compliance therewith. Airport Revenues The Sponsor shall maintain a fee and rental structure for the facilities and services at the Airport which will make the Airport as self-sustaining as possible under the circumstances existing at the particular Airport, taking into account such factors as the volume of traffic and economy of collection. All revenues generated by the Airport (and any local taxes established after Dec 30, 1987), will be expended by it for the capital or operating costs of the Airport; the local airport system; or the local facilities which are owned or operated by the owner or operator of the Airport and which are directly or substantially related to the actual air transportation of passengers or property, on or off the Airport. Disposal of land 1) For land purchased under a grant for airport development purposes (it is needed for aeronautical purposes, including runway protection zones, or serve as noise buffer land; and revenue from the interim use of the land contributed to the financial self-sufficiency of the Airport), the Sponsor shall apply to the State and FAA for permission to dispose of such land. If agreed to by the State and/or FAA, the Sponsor shall dispose of such land at fair market value and make available to the State and FAA an amount that is proportionate to the State and FAA's share of the cost of the land acquisition. That portion of the proceeds of such disposition, which is proportionate to the share of the cost of acquisition of such land, shall be (a) reinvested in another eligible airport development Project or Projects approved by the State and FAA or (b) be deposited to the Aviation Trust Fund if no eligible Project exists. 2) Disposition of such land shall be subject to the retention or reservation of any interest or right therein necessary to ensure that such land will only be used for purposes which are compatible with noise levels associated with operation of the Airport. Page 9 of 20 EXHIBIT B General Provisions Employment of Consultants Grant Number E4FSS 01E TOWN OF MARANA Marana Regional Airport The term consultant, as used herein, includes planners, architects and/or engineers. If a consultant is to be used for this Project, the Sponsor agrees to consider at least three (3) consultant firms. If the Sponsor has contracted with or will contract with a consultant on a retainer basis, the Sponsor assures to the State that prior to entering such a contract, at least three (3) consultants were or will be considered. The Sponsor shall submit to the State, for review and approval, a copy of the request for proposals and/or request for qualifications, and the proposed consultant contract prior to its execution and upon award of the contract, a fully executed copy. All requests for qualifications and requests for proposals shall be in accordance with A.R.S. 34, Chapters 1, 2 and 6, and shall include a list of projects and project locations to be awarded project contracts. rnntrnrtc 1) The Sponsor as an independent entity and not as an agent of the State may obtain the services required in order to fulfill the work outlined in the Project Description as approved by the State for funding in the Airport Capital Improvement Program. All contracts awarded to accomplish the project work described in this Agreement shall state: a) The name of the consultant authorized to perform the work and to communicate on behalf of the Sponsor; b) The Sponsor must insure that contracts issued under this Agreement comply with the provisions of Arizona Executive Order 75-5 as amended by Arizona Executive Order 2009-9, relating to equal opportunity; c) The terms for termination of the contract either for failure to perform or in the best interest of the Sponsor; d) The duly authorized representatives of the State shall have access to any books, documents, papers and records of the consultant and/or contractor which are in any way pertinent to the contract for a period of five years, in accordance with A.R.S. 35-214, for the purpose of making inspections, audits, examinations, excerpts and transcriptions. 2) All contracts shall stipulate and make clear: a) The responsibilities of the consultant to gain authorization for changes on the Project which may have an affect on the contract price, scope, or schedule; b) That all construction contractors and sub -contractors hired to perform services, shall be in compliance with A.R.S. 32, Chapter 10. c) That any materials, including reports, computer programs or files and other deliverables created under this Agreement are the sole property of the Sponsor. That these items shall be made available to the public. The Contractor/Consultant is not entitled to a patent or copyright on these materials and may not transfer the patent or copyright to anyone else. Page 10 of 20 Grant Number E4FSS HE TOWN OF MARANA Marana Regional Airport d) That any travel shall be reimbursable by the State only within the rules and costs in accordance with the State of Arizona Travel Policy. 3) Liability of Subcontractors 1) It shall be the responsibility of the Sponsor to ensure through contractual agreement that any independent contractor, subcontractors, or sub consultants utilized by the Sponsor, defend, indemnify, save, and hold harmless the State and any of their departments, divisions, agencies, officers, or employees who may be obligated to pay by reason of any liability imposed upon any of the above for damages arising out of any error, negligence, omissions, or act of the independent contractor, subcontractor, or sub consultant. Conflict of Interest Each consultant submitting a proposal shall certify that it shall comply with, in all respects, the rules of professional conduct set forth in Arizona Administrative Code R4-30-301. In addition, a conflict of interest shall be cause for disqualifying a consultant from consideration; or terminating a contract if the conflict should occur after the contract is made. A potential conflict of interest includes, but is not limited to: 1) Accepting an assignment where duty to the client would conflict with the consultant's personal interest, or interest of another client. 2) Performing work for a client or having an interest which conflicts with this contract. Reports 1) Reimbursement Requirements a). The Sponsor shall submit quarterly Grant Reimbursement Requests (GRR's) to the Aeronautics Grant Manager after the date of the grant agreement has been signed by both Sponsor and State. b). The Sponsor shall prepare quarterly (GRR) forms with the appropriate invoices attached which clearly indicate the project's progress to date and the amount of reimbursement due by virtue of that progress. All GRR's for payment shall be for work completed unless otherwise agreed to by State. (i). The State has the right to withhold reimbursement payments if the Sponsor does not fill out the State GRR form correctly. If the State does decide to withhold payments to the Sponsor for any reason, it must provide written notification and an explanation to the Sponsor within ten (10) days of the date of the invoice submitted. c). The State has the right to suspend any current or future grants should the Sponsor neglect to make a grant reimbursement request after 180 days as stated on the Projected Reimbursement Requests / State Cash Flow section of the grant agreement under Exhibit C, Schedule 2. d). An Airport may be awarded a pavement management agreement through the State's Airport Pavement Management System (APMS Program). Sponsors receiving APMS treatment will be responsible for 10% of the eligible construction cost. Outstanding balances after final costs reconciliation shall be paid to the State upon Page 11 of 20 Grant Number E4FSS HE TOWN OF MARANA Marana Regional Airport written notice. Any unpaid balance by the Sponsor can result in suspension of participation in the State's Airport Pavement Management System and State/Local Grants. 2) The Sponsor shall submit monthly status reports during planning, shall submit monthly status reports during design, and shall submit weekly reports during construction. All reports shall reflect, at a minimum, the progress accomplished in relation to the Grant and Project schedules and milestones, the reasons for any changes, and the recommended corrections of problems encountered. Upon completion of the Project, the Sponsor shall submit a letter to the State specifying that the Project has been completed to their satisfaction and that the consultant and the contractor have completed their contractual responsibilities. Changes Any changes to the consultant contract, authorized by the Sponsor, that include additional funds, time and/or scope, shall be by amendment and shall be approved by the State prior to being made in order to be eligible for reimbursement. Approval of a change by the State shall not obligate the State to provide reimbursement beyond the maximum funds obligated by this Agreement. Any increase to the amount of funds authorized hereunder, to the expiration date of this agreement, or to the scope of work included in this agreement must be by formal amendment, and signed by all parties. Any changes to the contract documents, authorized by the Sponsor, must be approved by the State prior to any changes being made in order to be eligible for reimbursement. Audit Upon completion of the Project, the Sponsor agrees to have an audit performed. The audit examination may be a separate project audit or in accordance with the Single Audit Act of 1984 (Single Audit). If the Sponsor is required under law to have a Single Audit, this Project shall be considered for inclusion in the scope of examination. The Sponsor shall keep all project accounts and records which fully disclose the amount and disposition by the recipient of the proceeds of the grant, the total cost of the Project in connection with which the grant is given or used, and the amount or nature of that portion of the cost of the Project supplied by other sources, and such other financial records pertinent to the Project. The accounts and records will be kept in accordance with A.R.S. 35-214. In any case in which an independent audit is made of the accounts of a Sponsor relating to the disposition of the proceeds of a grant relating to the Project in connection with which the grant was given or used, it shall file a certified copied of such audit with the State not later than six (6) months following the close of the fiscal year in which the audit was made. The Sponsor shall make available to the State or any of their other duly authorized representatives, for the purpose of audit and examination, any books, documents, papers and records of the recipient that are pertinent to the grant. The Sponsor further agrees to provide the State a certified copy of the audit report. The State is to determine the acceptability of this audit. Suspension If the Sponsor fails to comply with any conditions of this Agreement, the State, by written notice to the Sponsor, may suspend participation and withhold payments until appropriate corrective action has been taken by the Sponsor. Costs incurred during a period of suspension may not be eligible for reimbursement by the State. Page 12 of 20 Grant Number E4FSS 01E TOWN OF MARANA Marana Regional Airport Failure to Perform If the Sponsor fails to comply with the conditions of this Agreement the State, may by written notice to the Sponsor, terminate this Agreement in whole or in part. The notice of termination will contain the reasons for termination, the effective date, and the eligibility of costs incurred prior to termination. The State shall not reimburse any costs incurred after the date of termination. Termination for Convenience When the continuation of the Project will not produce beneficial results commensurate with the further expenditure of funds or when funds are not appropriated or are withdrawn for use hereunder, the State may terminate this Agreement. In the case where continuation of the Project will not produce beneficial results, the State and the Sponsor shall mutually agree upon the termination either in whole or in part. In the case where funds are no longer available or have been withdrawn or not appropriated, or the Project is no longer in the State's best interest, the State shall have the right of termination as its sole option. The State shall not reimburse any costs incurred after receipt of the notice of termination. The Governor pursuant to A.R.S. Section 38-511 hereby puts all parties on notice that this Agreement is subject to cancellation. Waiver by State No waiver of any condition, requirement or right expressed in this Agreement shall be implied by any forbearance of the State to declare a default, failure to perform or to take any other action on account of any violation that continues or repeats. Compliance with Laws The Sponsor shall comply with all Federal, State and Local laws, rules, regulations, ordinances, policies, advisory circulars, and decrees that are applicable to the performance hereunder. Arbitration In the event of a dispute, the parties agree to use arbitration to the extent required by A.R.S. Section 12-1518. Jurisdiction Any litigation between the Sponsor and the State shall be commenced and prosecuted in an appropriate State court of competent jurisdiction within Maricopa County, State of Arizona. Excess of Payments If it is found that the total payments to the Sponsor exceed the State's share of allowable project costs, the Sponsor shall promptly return the excess to the State. Final determination of the State's share of allowable costs shall rest solely with the State. Any reimbursement to the Sponsor by the State not in accordance with this Agreement or unsubstantiated by project records will be considered ineligible for reimbursement and shall be returned promptly to the State. State Inspectors Page 13 of 20 Grant Number E4FSS 01E TOWN OF MARANA Marana Regional Airport At any time and/or prior to final payment of funds for work performed under this Agreement, the State may perform an inspection of the work performed to assure compliance with the terms herein and to review the workmanship of the Sponsor's contractors and/or consultants. No inspector is authorized to change any provisions of this Agreement or any provisions of Agreements between the Sponsor and the Sponsor's contractor and/or consultant. Indemnification The State of Arizona, acting by and through the Arizona Department of Transportation, does not assume any liability to third persons nor will the Sponsor be reimbursed for the Sponsor's liability to third persons resulting from the performance of this Agreement or any subcontract hereunder. The Sponsor shall indemnify and hold harmless the State, any of their departments, agencies, officers and employees from any and all liability, loss or damage the State may suffer as a result of claims, demands, costs or judgments of any character arising out of the performance or non-performance of the Sponsor or its independent contractors in carrying out any provisions of this Agreement. In the event of any action, this indemnification shall include, but not be limited to, court costs, expenses of litigation and reasonable attorney's fees. Required Provisions Deemed Inserted Each and every provision of law and clause required by law to be inserted in this Agreement shall be read and enforced as though it were included herein, and if through mistake or otherwise any such provision is not inserted, or is not correctly inserted, then upon the application of either party, this Agreement shall forthwith be physically amended to make such insertion or correction. Property of the Sponsor and State Any materials, including reports, computer programs or files and other deliverables created under this Agreement are the sole property of the Sponsor. The Contractor/Consultant is not entitled to a patent or copyright on these materials and may not transfer the patent or copyright to anyone else. The Sponsor shall give the State unrestricted authority to publish, disclose, distribute and otherwise use at no cost to the State any of the material prepared in connection with this grant. At the completion of the project, the Sponsor shall provide the State with an electronic copy, in a format useable by the State, and one hard copy in a format useable by the State, of final plans, specifications, reports, planning documents, and/or other published materials as produced as a result of this project. Title VI List of Pertinent Nondiscrimination Authorities During the performance of this Agreement, the Sponsor, for itself, its assignees, and successors in interest (hereinafter referred to as the "Sponsor") agrees to comply with the following non-discrimination statutes and authorities, Including but not limited to: 1) Title VI of the Civil Rights Act of 1964 (42 U.S.C. §2000d et seq., 78 stat. 252), (prohibits discrimination on the basis of race, color, national origin); 2) 49 CFR part 21 (Non-discrimination In Federally -Assisted Programs of The Department of Transportation — Effectuation of Title VI of The Civil Rights Act of 1964); Page 14 of 20 Grant Number E4FSS HE TOWN OF MARANA Marana Regional Airport 3) The Uniform Relocation Assistance and Real Property Acquisition Policies Act of 1970, (42 U.S.0 § 4601), (prohibits unfair treatment of persons displaced or whose property has been acquired because of Federal or Federal -aid programs and projects); 4) Section 504 of the Rehabilitation Act of 1973, (29 U.S.C. § 794 et seq.), as amended, (prohibits discrimination on the basis of disability); and 49 CFR part 27; 5) The Age Discrimination Act of 1975, as amended, (42 U.S. C. § 6101 et seq.), (prohibits discrimination on the basis of age); 6) Airport and Airway Improvement Act of 1982, (49 USC § 471, Section 47123), as amended, (prohibits discrimination based on race, creed, color, national origin, or sex); 7) The Civil Rights Restoration Act of 1987, (PL 100-209), (Broadened the scope, coverage and applicability of Title VI of the Civil Rights Act of 1964, The Age Discrimination Act of 1975 and Section 504 of the Rehabilitation Act of 1973, by expanding the definition of the terms "programs of activities' to include all the programs or activities of the Federal -aid recipients, sub -recipients and contractors, whether such programs or activities are Federally funded or not); 8) Titles II and III of the Americans with Disabilities Act of 1990, which prohibit discrimination on the basis of disability in the operation of public entities, public and private transportation systems, places of public accommodation, and certain testing entities (42 U.S.C. §§ 12131-12189) as implemented by Department of Transportation regulations at 49 CFR parts 37 and 38; 9) The Federal Aviation Administration's Non-discrimination statute (49 U.S.0 § 47123) (prohibits discrimination on the basis of race, color, national origin, and sex); 10) Executive Order 12898, Federal Actions to Address Environmental justice in Minority Populations and Low - Income Populations, which ensures discrimination against minority populations by discouraging programs, policies, and activities with disproportionately high and adverse human health or environmental effects on minority and low-income populations; 11) Executive Order 13166, Improving Access to Services for Persons with Limited English Proficiency, and resulting agency guidance, national origin, discrimination includes discrimination because of limited English proficiency (LEP). To ensure compliance with Title VI, you must take reasonable steps to ensure that LEP persons have meaningful access to your programs (70 Fed. Reg. at 74087 to 74100); 12) Title IX of the Education Amendments of 1972, as amended, which prohibits you from discrimination because of sex in education programs or activities (20 U.S.0 1681 et. Seq.). 13) All parties shall comply with all applicable federal, state, county, cities, and local laws, rules, regulations, and assurances in addition to all applicable provisions of Title 14 (Aeronautics and Space Chapter 1 — Federal Aviation Administration, Department of Transportation) and Title 49 (United States Department of Transportation) and other applicable Codes of Federal Regulations where and when relevant. Page 15 of 20 Grant Number E4FSS 01E TOWN OF MARANA Marana Regional Airport EXHIBIT C Specific Provisions and Project Schedules Provisions for Environmental Document Financial Cost Categories The Sponsor shall segregate and group project costs in categories as follows: 1) "Environmental Document" (as applicable), including consulting services. 2) "Sponsor Administration" directly associated with this Project (not to exceed 5% of consulting service costs). 3) "Sponsor Force Account" contribution (if applicable). 4) "Other" with prior approval of the State. Environmental Agreements 1) The Sponsor shall include in all published material in connection with the Environmental Document a notice that the material was prepared under a grant provided by the Arizona Department of Transportation. The terms, conditions and assurances shall remain in effect until grant closure. The Sponsor shall give the State unrestricted authority to publish, disclose, distribute and otherwise use any of the material prepared in connection with this grant. 2) The Sponsor shall make Environmental Document material available for examination by the public and agrees that no material prepared with funds under this Project shall be subject to copyright. Approval of this Project grant or approval of the environmental document materials developed as a part of this grant does not constitute or imply assurance or commitment on the part of the State to approve pending or future application for a State grant or funding. 3) The Sponsor shall complete all environmental documents in accordance with FAA Order 5050.413 (National Environmental Policy Act Instructions for Airport Projects) & FAA Order 1050.1E (Policies and Procedures for Considering Environmental Impacts) or revisions, applicable federal and state regulations, orders, policies, and requirements. The Sponsor may not accomplish the final acceptance of the plan until the State has reviewed and commented on the work performed. The comments provided by the State shall not be construed as approval of the environmental document. 4) At the completion of the Project, the Sponsor agrees to provide an electronic copy, in a format usable by the State of final environmental documents, and/or other published materials produced as a result of this environmental Project. Final reimbursement will not be made until the State receives all required documentation. Page 16 of 20 Grant Number E4FSS OIE TOWN OF MARANA Marana Regional Airport Project Schedules for Environmental Document The Schedule Forms are intended to identify and monitor project scope, costs, and basic milestones that will be encountered during various phases of the Project. The Sponsor shall complete these three schedules showing the project description and total costs, project reimbursements (cash flow) schedule and project milestones. Schedule One shows the total Project estimated costs associated with each share - State and Federal and Local. Schedule Two shows a projected cash flow for State funds only. The Sponsor is to estimate requests to the State for Project reimbursement. Schedule Three shows anticipated dates of Project milestones. These schedules will be used to keep track of the Project's progress. Be sure to develop realistic schedules. As the project progresses, and the original reimbursement schedule and or milestone dates change, the Sponsor must submit a revised Schedule to the State for approval. Schedule One Project Description and Funding Allocation Detailed Project Description: Air Traffic Control Tower Environmental Assessment FAA AI P # 3-04-0058-029-2023 Project Cost Category Total Estimated Project Cost Estimated Local Share Estimated Federal Share Estimated State Share* Environmental Document $457,206 $20,437 $416,332 $20,437 Sponsor Administration** $9,331 $417 $8,497 $417 Sponsor Force Account Work*** $ $ $ $ Other $ $ $ $ Total Project Costs $466,537 $20,854 $424,829 $20,854 *Total of this column to be used in Schedule Two. ** Sponsor Administration is not eligible for reimbursement above 5% of the Environmental Document costs. *** All force account work is to be approved by the State prior to the grant agreement being signed. Page 17 of 20 Grant Number E4FSS HE TOWN OF MARANA Marana Regional Airport Schedule Two Environmental Document Reimbursement Schedule The Sponsor must complete this Project Reimbursement Schedule showing the projected cash flow of State grant funds only for this Project. Projections must include all consultant and contractor services. The reimbursement schedule should be a realistic schedule and will be used to keep track of a project's progress. Reimbursement requests must be submitted regularly by the Sponsor while the grant is active. The cash flow should reflect when a request is submitted to the State, not when invoices are paid by the Sponsor. Inctrnrtinnc- 1) For "Total State Funds" below, enter the Total Project Costs/Estimated State Share from Schedule One. 2) For each month/year, indicate the projected reimbursement request amount for State Funds Only (use whole dollars only, e.g. $540 or $1,300). 3) Continue the process by entering a Zero (0) in the month/year for which no reimbursement is anticipated and/or a dollar amount of the reimbursement, until the total State funds are accounted for in the cash flow. Total State Funds: $ 20,854.00 Projected Reimbursement Requests / State Cash Flow Calendar Year Jan Feb Mar Apr May Jun 2023 $0 $0 $o $o $o $0 2024 $2,642 $1,517 $1,517 $1,517 $1,517 $1,517 2025 $1,525 $ $ $ $ $ 2026 $ $ $ $ $ $ 2027 $ $ $ $ $ $ Calendar Year Jul Aug Sep Oct Nov Dec 2023 $o $o $ $ $ $ 2024 $1,517 $1,517 $1,517 $1,517 $1,517 $1,517 2025 $ $ $ $ $ $ 2026 $ $ $ $ $ $ 2027 $ $ $ $ $ $ Page 18 of 20 Grant Number E4FSS WE TOWN OF MARANA Marana Regional Airport Grants expire 4 years from the date of the grant offer. The Sponsor shall schedule the work to be completed within the 4 years. Page 19 of 20 Schedule Three Environmental Document Milestones Milestone Duration Guidelines Grant Number E4FSS HE TOWN OF MARANA Marana Regional Airport The below duration periods are intended to provide guidelines for you to consider. These are average time periods (in calendar days), but it is understood these periods may vary by Sponsor and Project, and are subject to modification. If an entry on the form is not applicable write N/A. 1) The Consultant Selection Phase for all Projects, regardless of type, is approximately ninety (90) days but should not exceed one hundred eighty (180) days. 2) The Environmental Document Phase is subject to the type and complexity of the Project, however, most environmental documents can be accomplished within five hundred forty (540) days to seven hundred twenty (720) days. 3) State review periods should be thirty (30) days. Environmental Document Milestone Schedule Milestones Duration # of Days Start Date Completion Date Proposed Proposed Consultant Selection Phase mm/dd/year mm/dd/year Submit Scope for State Review/Approval* 30 1/18/23 3/1/23 Submit Contract for State Review/Approval Award Consultant Contract 0 4/2/23 Environmental Phase Sponsor Issue Notice to Proceed 1 4/1/23 4/1/23 Submit Draft Environmental Document to FAA and State for review 45 9/2/24 11/1/24 Submit Final Environmental Documentation and Federal Approvals 1 1/6/25 1/7/25 Submit Final Reimbursement Request and Sponsors Closeout Letter 1 1/30/25 1/31/25 * The solicitation for qualifications and the resulting service agreements must contain a list of projects, including this grant project, per A.R.S. 34, Chapter 6. Page 20 of 20